Shutdown-Proof Your Federal Contract: How Smart Contractors Stay Paid, Protected, and Prepared
If you're a small business with federal contracts, you’re already familiar with the anxiety that comes with a government shutdown. Payments get delayed. CORs disappear. Confusion reigns. But here’s the thing, shutdowns don’t have to derail your performance, your cash flow, or your CPARS rating. The latest 2025 guide on Protecting Federal Contracts During a Government Shutdown lays out a clear playbook for how to protect your work, your people, and your pipeline. And if you’re in the 8a contracts services world, or eyeing disabled veteran government contracts, you need to be especially sharp right now.
Here’s what you need to know, why it matters, and what steps to take before things go off the rails.
Let’s start with the basics: during a shutdown, federal agencies follow OMB contingency plans that halt “non-excepted” activities. That means if your contract isn’t fully funded or tied to an excepted function (like national security), it’s at risk for a stop-work order. Don’t guess. Don’t assume. Reach out to your Contracting Officer (CO) in writing and confirm the funding status of each CLIN. If the CO is furloughed or unresponsive, still send the message, it proves you acted in good faith and protects you later.
Now for the kicker: continuing to work without confirmation could violate the Antideficiency Act. That’s not just a paperwork issue, it’s a serious compliance red flag. So if you’re working under a women owned small business certification or using sba 8a certification services to support agency work, the last thing you want is to be accused of incurring unauthorized costs.
Why This Shutdown Playbook Matters More Than Ever
Small and mid-sized government contractors are disproportionately impacted by these funding lapses. You don’t have the luxury of floating payroll for weeks while your invoices sit unpaid. You also don’t want to tank your CPARS over something outside your control. That’s why shutdown planning isn’t optional, it’s survival.
Key takeaways from the guide include:
Email scripts to notify COs of work stoppage, request formal direction, and resume work once funding returns.
A shutdown impact log to track idle labor, delayed deliveries, missed inspections, and CO correspondence.
REA preparation checklists to recover costs under FAR clauses like 52.242-15 (Stop-Work) and 52.243-1 (Changes).
CPARS protection strategies that show you weren’t the cause of delays, and in fact, went above and beyond.
If you're navigating the government contracting certification process, these records can also protect your eligibility. A delayed milestone without justification could damage your track record and make future 8a certification assistance harder to justify.
What You Can Do Right Now
Here are practical steps to take, even if your contract is still humming along:
Audit your current contract backlog. Know which ones are fully funded, incrementally funded, or tied to non-excepted work.
Prep email templates. Use the ones in the guide or customize your own so you’re ready to send when things slow down.
Create a shutdown cost code in your accounting system. This lets you separate out standby labor, equipment, or material delays cleanly when it's time to build your REA.
Keep a daily log. Even if the CO goes dark, you’ll have the evidence to show when work stopped, what was affected, and what you did to mitigate damage.
Review FAR clauses in your contract. Know if 52.242-15 (Stop-Work Order), 52.242-17 (Government Delay), or 52.249-14 (Excusable Delays) applies.
Train your team on communication protocols. Make sure your PMs and billing staff know they can’t continue work without written CO guidance.
Final Word: Don’t Be Passive, Be Documented
The federal government may hit pause, but your obligation to protect your contract doesn’t. The contractors who weather shutdowns with their CPARS intact aren’t lucky, they’re prepared. They communicate. They document. They mitigate.
And they don’t just survive shutdowns. They build trust with agencies that pays off down the road.
If you’re pursuing federal contracting certifications like women business certification or disabled veteran small business certification, protecting your past performance is essential. That’s what source selection panels look at next time.
Want more clarity on how to protect your GovCon business when agencies freeze up? Check out our related post: When the Government Shuts Down, Smart Contractors Team Up for more templates and impact tracking tips.
If you aren't a Squared Compass partner, what are you waiting for? From getting your business set up with specific government set aside programs at both the State and Federal level, to being empowered by a Fractional Capture team to win government contracts, to receiving tailored government contract opportunities Squared Compass delivers immense value which helps propel our partners to success. Schedule a chat with our team today.
